Next Article in Journal
Correction: Fujii, K. Bidirectional Seismic Energy Input to an Isotropic Nonlinear One-Mass Two-Degree-of-Freedom System. Buildings 2021, 11, 143
Previous Article in Journal
Numerical Analysis of Piled-Raft Foundations on Multi-Layer Soil Considering Settlement and Swelling
 
 
Font Type:
Arial Georgia Verdana
Font Size:
Aa Aa Aa
Line Spacing:
Column Width:
Background:
Article

Exploring the Barriers against Using Cryptocurrencies in Managing Construction Supply Chain Processes

1
Department of Civil Engineering, Yildiz Technical University, Istanbul 34220, Turkey
2
Department of Civil, Architectural, and Environmental Engineering, Illinois Institute of Technology, Chicago, IL 60616, USA
*
Author to whom correspondence should be addressed.
Buildings 2022, 12(3), 357; https://doi.org/10.3390/buildings12030357
Submission received: 16 February 2022 / Revised: 11 March 2022 / Accepted: 14 March 2022 / Published: 15 March 2022
(This article belongs to the Section Construction Management, and Computers & Digitization)

Abstract

:
Various stakeholders are involved in managing supply chain processes in construction. Suppliers can hardly tolerate upfront costs when faced with flaws in the payment pipeline. This is a serious problem in building construction that uses a large variety of materials as opposed to civil construction that requires fewer types of materials. Alternative secure payment systems are needed, and the use of cryptocurrencies can be an option. However, cryptocurrencies are seldom used in building construction projects due to several challenges that are mostly ignored in the existing literature. To fill this gap, this study investigates the use of cryptocurrencies in construction supply chains as an alternative payment solution to improve the financial performance of the stakeholders by taking advantage of this economical and traceable financial transaction system. The study involves exploratory, descriptive, and empirical survey research. Accordingly, a literature review, focus group discussions, and statistical analyses (Friedman test, Wilcoxon test, and Mann–Whitney U test) were performed. The results imply that a lack of technical knowledge about cryptocurrencies, fluctuations in the value of cryptocurrencies, limited market opportunities, security gaps, personal information required by cryptocurrency systems, no assurance of permanent use, and government actions limiting the use of cryptocurrencies were the most significant barriers against using cryptocurrencies in construction supply chain management. The findings are expected to provide critical information to construction professionals and regulatory agencies about the potential advantages and shortcomings of cryptocurrencies, hence motivating policymakers to create strategies that minimize the concerns of construction professionals about using cryptocurrencies in the building construction industry.

1. Introduction

Payment problems such as delayed payments or non-payment are part of the inherent culture in the construction industry [1] and could exacerbate efficient supply chain practices [2], especially in the building construction industry that makes use of many different types of materials. Since payments and material delivery are linked to each other, blockage of the payment pipeline could affect all parties on the supply chains [3], which are characterized by many uncertainties [4]. Evidence suggests that the timing of the payments is a key element of the profitability and performance of construction firms [5]. However, the construction industry has long been regarded as having poor payment practices [6], eventually causing schedule delays [7], cost overruns [8], and disputes between stakeholders [9]. Additionally, the industry has a conditional payment settlement culture in that the contractor pays the material dealers only if or when paid by the construction owner, which can be considered to be quite distinctive compared to payments in other industries [1]. Particularly small and medium-sized enterprises (SMEs), such as material suppliers to construction contractors [10], can hardly tolerate upfront costs when faced with payment delays that cause severe fluctuations in their cash flow [11]. Improving payment performance in building construction projects may not only ensure stable and predictable cash flows for all parties on the supply chain, but may also increase the profitability of projects through better cost, time, and claim performance.
The literature on payment practices in the construction supply chain heavily focuses on the potential causes, effects, and solutions [1,12,13,14]. Several data-driven systems have been proposed to improve the performance of payment mechanisms in construction supply chains. These include the development of an information technology (IT) system to help select the most appropriate payment mechanism [15], the use of Markov chains to estimate the probability of being paid [16], and the adoption of cash flow control methods that estimate delays in owners’ payments [17]. Recent studies emphasize the need to integrate advanced technologies, mainly blockchain and smart contracts, to ensure the security of payments. For instance, Chong and Diamantopoulos [18] proposed an automatic payment system that includes the use of smart contracts, blockchain technology, and building information modeling after the completion of contractual obligations. By using the same technologies, Sigalov et al. [19] also proposed an automated payment-based contract administration mechanism to address late or non-payment issues. Similarly, Ahmadisheykhsarmast and Sonmez [20] developed a transparent, timely, and secure payment system for construction projects using smart contracts. The researchers mainly used fiat currencies in these studies and addressed several limitations of using cryptocurrencies for financial transactions such as a lack of regulations, lack of tax procedures, and extreme fluctuations in the value of cryptocurrencies [19,20]. Despite such barriers, the potential opportunities created by blockchain technology and smart contracts have been frequently investigated recently [21,22,23,24]. Nevertheless, it is noteworthy that the barriers against adopting cryptocurrencies and the related opinions of construction professionals have been generally overlooked in the literature. The use of cryptocurrencies could provide payment security in addition to ensuring product compliance and authenticity [25]. According to Ahmadisheykhsarmast and Sonmez [20], with the integration of cryptocurrencies into smart contracts, the insolvency of suppliers caused by cash-flow issues originating from late payments in construction projects can be prevented.
This study aims to identify and evaluate the barriers against using cryptocurrencies in construction supply chains and determine the opinions of construction professionals about this payment alternative. The contribution of the study is twofold. First, investigating and clearly stating the most significant barriers against adopting cryptocurrencies could provide guidance to professional/trade associations and government agencies in developing strategies for its use as an alternative payment option. Based on blockchain infrastructure, such a payment option can be integrated into smart contract and BIM technologies. On the other hand, the construction industry is known for being a slow mover in the adoption of new technologies. It is obvious that the opinions of professionals are always an important factor in the decision to use a new technology. Guidelines and regulations can be developed only by including the opinions of construction professionals. For that reason, understanding the opinions of construction professionals about the use of cryptocurrencies in construction supply chains is also a major objective of the study presented in this paper.
To achieve the objectives of the study, an exploratory research strategy was first pursued by means of a comprehensive literature survey. However, because the literature about the barriers against using cryptocurrencies in construction supply chains is rather limited, this was followed by a descriptive research strategy that involved a focus group discussion where (1) the barriers against using cryptocurrencies were classified into four categories, namely technical, trust, market, and regulatory; and (2) a questionnaire was prepared to seek the opinions of construction professionals about the use of cryptocurrencies in construction supply chains. Finally, an empirical research strategy was used to administer a survey to construction professionals and to analyze the data collected (i) to identify the most significant barriers; (ii) to conduct the Friedman and Wilcoxon tests to find whether the mean ranks of barriers in each barrier category are statistically different or not; and (iii) to perform the Mann–Whitney U test to examine differences in respondents’ opinions with respect to their expertise, knowledge of basic principles of economics, and experience in the use of cryptocurrencies. Overall, this study is expected to contribute to the literature about payment practices in construction supply chains, and in particular about the use of cryptocurrencies in this process. The impact is expected to be particularly pronounced in the building construction industry that involves a multitude of suppliers providing materials to the contractor.

2. Literature Review

Delayed payment to suppliers is one of the cultural features of the construction industry in most countries [2] and collaboration between suppliers and contractors is essential for successful project management [26]. Abdul Kadir et al. [27] highlighted that delays in payments to suppliers impact the timely delivery of materials, which in turn, causes a decline in construction productivity. Delayed payment and non-payment often result in conflicts and eventually legal disputes in the construction industry and exacerbate the difficulties encountered in the supply chain process [3]. Due to the integrated and dependent characteristics of the processes in the construction supply chain, the timing of the payments has a significant impact on the performance and sustainability of the payment processes [5]. A dispute between a contractor and a supplier can aggravate the smooth flow of payments and the smooth flow of material deliveries not only in a particular case, but also in other cases where the contractor is dealing with suppliers who were not even involved in the said dispute [28,29]. Chen [30] performed semi-structured interviews to explore the payment behavior of the parties to a construction project and found that the payment behavior of contractors relative to suppliers depends on the behavior of construction owners vis-a-vis contractors. Pettigrew [31] highlighted that the pay-when-paid and pay-if-paid culture in the construction industry creates serious problems between contractors and suppliers [32]. All these findings reported in the literature show the need for secure and timely payment procedures that eliminate the current cash flow problems experienced by suppliers and that establish a healthy and harmonious supply chain with no conflicts and disputes between the parties.
There has been a plethora of studies in the literature to address payment problems in construction supply chain management. In this context, Chen [33] investigated the cash-flow performance of contractors and evaluated the impacts of the payment models used by the owner on the cash flow of the contractor. Similarly, Andalib et al. [17] developed a cash flow estimation model to highlight possible delays in the payments received from the owner. The researchers created a budget realization index that is an indicator of the payment behavior of the owner and provided evidence for the applicability of the approach by using it in four case studies in Iran. To ensure a stable and predictable cash-flow for all supply chain parties, Motawa and Kaka [15] developed an IT system to help supply chain stakeholders to identify the most suitable payment mechanism. The researchers found that the proposed automated system satisfied the expectation of all supply chain parties. Tran and Carmichael [16] calculated the probability of timely payment after a claim, helping the sub-contractor to foresee potential cash-flow problems. Apart from cash-flow problems, some researchers focused on erratic payment patterns relative to relationship-based issues. In this context, Loosemore and Lim [34] examined organizational unfairness such as payment issues and supply chain exploitation in the Australian construction industry and found that procedural and distributive justice are low in the industry particularly related to sub-contractors and suppliers. Martin and Benson [35] investigated the quality of the relationship between subcontractors and contractors in construction supply chains and found that sub-contractors considered timely payment to be among the key factors in this relationship. Abidin and Ingirige [3] examined the opportunities to improve construction supply chains and discovered that delayed payments and non-payment cause serious disruptions in material delivery. Koc and Gurgun [36] performed a systematic literature review to extract stakeholder-associated life cycle risks in construction supply chains and found that late payment is among the critical risks and that supplier vulnerability has been overlooked in the literature. Morrison and Trushell [37] focused on the ownership of materials based on payment, delivery and contractual arrangements and addressed the need to develop a robust legal structure for materials located off site. Riazi et al. [38] investigated payment practices in an industrialized building system (IBS) project in Malaysia and found that poor payment mechanism is the major contributor to low IBS adoption. In addition to addressing payment-related issues directly, some researchers highlighted other aspects of supply chain management to improve the performance of construction projects such as sustainable supply chain management [39,40,41], robust supplier selection [42,43], supplying energy to green building projects [44], and more commonly, digitalization in supply chains [45,46,47].
Over the last couple of years, the use of blockchain-based technologies received considerable attention to solve several issues in construction supply chains. These studies included the examination of potential advantages and disadvantages of blockchain-based distributed ledger technologies (DLT) to improve supply chain management practices. For instance, Li and Kassem [48] conducted semi-structured interviews with industry professionals and recommended the enactment of new financial regulations to encourage the adoption of DLT in supply chain management. Similarly, Li et al. [49] performed a systematic literature survey about the practical use of blockchain technology in the built environment and pointed out that fluctuations in cryptocurrency valuations could be a challenge when cryptocurrencies are used in construction projects. Another study that addressed the potential advantages and the limitations of blockchain technology was performed by Nawari and Ravindran [50] who found that construction firms’ focus on return on investment, the complexity of construction projects, the poorly trained construction personnel, and the legal uncertainties constitute severe barriers against adopting digitalization. Likewise, Nanayakkara et al. [51] investigated the suitability of blockchain and smart contracts to solve payment problems in construction supply chains through an expert forum. The researchers found that these technologies can improve financial issues, payment issues, security of payments and ensure the legitimacy of long payment cycles in construction supply chains. In prefabrication supply chains, Bakhtiarizadeh et al. [52] emphasized the need for integrating blockchain and information management. They identified the channels required for effective information exchange between project parties using a questionnaire survey and found that blockchain technology has a positive impact on information management. Bayramova et al. [53] performed a scientometric analysis to explore the impacts of blockchain on supply chain resilience and recommended that regulators should identify and set basic standards for blockchain use. Albayati et al. [54] investigated the behavioral elements of the intentions of customers to use blockchain-based cryptocurrency transactions in supply chains other than construction supply chains. The researchers identified two powerful requirements that would encourage customer trust in blockchain-based cryptocurrencies: (1) regulatory support by the government, and (2) experience. On the other hand, Corbet et al. [55] conducted a systematic analysis of cryptocurrencies as financial assets, without focusing on a particular industry. The researchers found that legal, economic, and regulatory issues are major research gaps in this context.
Implementation of several technologies in supply chain management practices can help companies to enhance their competitive advantages in the sector [56]. However, supply chain practices have rarely benefited from the use of blockchain-based technologies, which is expected to increase in future [57]. Recently, some researchers have attempted to implement blockchain technology to improve supply chain practices in construction projects. For instance, Das et al. [58] presented a distributed blockchain-based framework and proposed an automated solution to initiate, validate, and execute interim payments in accordance with contract conditions. Tezel et al. [59] found that using blockchain technology to make payments is easier and more practical compared to other technologies in construction supply chain management such as tendering or project tokenization. By addressing the criticality of timely payments for the successful achievement of project objectives, Ahmadisheykhsarmast and Sonmez [20] proposed a smart contract system that automates the payment process and ensures secure payment between construction stakeholders. Likewise, Hamledari and Fischer [60] developed a model that integrates physical and financial assets in construction supply chains. They found that crypto assets have great potential to increase the integration between cash flows and product flows. Dakhli et al. [61] investigated the potential of using blockchain technology in the construction sector and found that blockchain implementation can result in an 8.3% cost saving in residential construction projects while Elghaish et al. [62] introduced a blockchain-based integrated project delivery framework for an automated financial system in construction projects and claimed that the proposed project delivery system was able to overcome many existing financial barriers.
This extensive literature review shows that payment issues in construction supply chains were investigated from a variety of perspectives and were directed to blockchain-based technologies. Most studies investigated the barriers or challenges encountered when using blockchain-based digital technologies but did not particularly focus on the use of cryptocurrencies by construction firms in their supply chains. In addition, there has been very few attempts to address the challenges encountered by construction professionals when using cryptocurrencies in construction supply chains, e.g., [19]. These facts imply that further exploration is necessary to understand the challenges, opportunities, barriers, benefits, and risks of using cryptocurrencies in construction supply chains and to ascertain the differences between the opinions of the professionals representing the construction industry. Government agencies and policymakers can safeguard project stakeholders against the risks of using cryptocurrencies, as the use of this method of payment becomes more widespread in the construction industry. This is particularly important for effective payment management in construction projects since the use of cryptocurrencies allows parties to pay each other without the traditional transaction formalities, expenses, and delays, hence improving supply chain management. In addition, examining the differences between the opinions of construction professionals who have different backgrounds (in terms of their profession, their knowledge of economic theories, and their experiences relative to using cryptocurrencies) can contribute to circumventing the barriers against using cryptocurrencies, hence generating competitive advantage in an industry where competitive pressures are high and the profit rate is low. Overall, this study is expected to fill the gap in the literature about cryptocurrency use in construction supply chains, and to inform government agencies in change of policymaking and construction professionals who manage construction projects about a new payment method (namely cryptocurrencies) that may allow them to improve current practices in supply chain management.

3. Research Methods

This study poses the following research questions:
  • What are the most significant barriers affecting the use of cryptocurrencies in construction supply chains?
  • Are the respondents’ opinions about the barriers significantly different from each other in each barrier category?
  • Do the respondents’ opinions about the barriers differ according to their expertise, knowledge of basic principles of economics, and experience?
Based on the study of Chileshe et al. [63], these questions are answered by means of a three-stage research design that involves conducting an exploratory survey in the first stage, a descriptive survey in the second stage, and an empirical survey in the third stage, as presented in Figure 1. Exploratory survey research (Stage 1) involves a literature review leading to an initial list of barriers against adopting cryptocurrencies in construction supply chains. In the second stage, descriptive survey research is performed through a focus group discussion to refine the list of barriers since there has been limited research studies on cryptocurrency adoption in construction projects. Finally, in the third stage, empirical survey research is conducted through a questionnaire survey and the use of several statistical analysis techniques to determine the importance of the barriers as well as the opinion differences between the participants. According to Chileshe et al. [63], the use of this triangulated approach is most appropriate in conducting research studies related to construction management. Figure 2 shows the research flow of this study. As seen in Figure 2 and explained in later subsections, this study’s research strategy involves (1) determining the scope of the research, (2) collecting the data, and (3) analyzing the data. Accordingly, this study performed a literature survey followed by a focus group discussion to determine the barriers against adopting cryptocurrencies in construction supply chains (Step 1). Construction professionals were contacted to collect data about the barriers against using cryptocurrencies (Step 2). Finally, the collected data were analyzed by using several statistical tests (Step 3). These steps are described in detail in the following sub-sections.

3.1. Research Scope (Step 1)

This step involves exploratory and descriptive survey research. The exploratory survey research involved a comprehensive literature review that was conducted to identify the initial list of barriers affecting the widespread use of cryptocurrencies in construction supply chains. While reviewing the literature, studies that were not directly related to the construction industry were also investigated due to the scarcity of the cryptocurrency literature about the construction industry. The barriers so identified were then refined in a descriptive survey research that made use of a focus group discussion that was performed by seven professionals who had extensive experience in construction supply chains. The size of the discussion group was adequate as Ajayi and Oyedele [64] recommended between 5 to 25 participants for constructive discussion sessions. The motivation was to refine and classify the barriers affecting cryptocurrency use in construction supply chains identified in the prior literature survey. Participants were selected based on purposive sampling and thus a detailed background investigation was performed for each of them [36]. The participants were expected to comply with the following requirements: (i) having at least 15 years of experience in the construction industry, (ii) dealing with supply chain processes in construction for at least 5 years, and (iii) having experience in using cryptocurrencies at least once. Eighteen barriers were identified at the end of the group discussions and were classified into four categories: technical, trust, market, and regulatory (Table 1).

3.2. Data Collection (Step 2)

A questionnaire survey was administered to professionals to collect their opinions about the use of cryptocurrencies in the construction supply chain. The survey consisted of two parts. In the first part, demographic characteristics and background knowledge were sought, while the importance of potential barriers against using cryptocurrencies were investigated in the second part using a five-point Likert scale (i.e., 1 = least important and 5 = extremely important). Even though some researchers adopted six-point [76] or seven-point Likert scales [77,78], a five-point Likert scale was adopted in this study due to its widespread use in surveys similar to the survey administered in this study [79,80,81]. The survey was sent to 357 construction professionals who were employed by Turkish contractors and whose attributes were in compliance with the aim of the study. These professionals were selected using random sampling [82]. A total of 306 responses were received out of which 284 responses were used in the study after screening the responses, providing a response rate of 80%. A variety of demographic characteristics such as age, gender, education level, expertise, position in the company, income level, experience, and knowledge of the basic principles of economic theories were sought in the first part [78,80,81] to investigate respondents’ differences in their opinion about each barrier. The respondents’ knowledge of the basic principles of economics was investigated with a question that asked whether the respondent had ever enrolled in at least one economics course during their undergraduate education or later in professional life.
A wide range of participants working in the construction industry were invited to participate in the survey. The distribution of the respondents’ professions is illustrated in Figure 3. Most of the respondents were either architects or engineers, and there were few participants who served in the health and safety, human resources, and legal departments of construction companies. Using this information, the respondents were categorized in two major groups “architects/engineers” and “others” for data analysis.
Table 2 shows participants’ other demographic characteristics. The majority of the respondents were male employees with 6–15 years of experience. Most of them were experienced in online shopping in their daily lives, which made them familiar with online payment transactions, and only a quarter of them used cryptocurrencies. Nearly half of the respondents attended economics courses during their college education or short courses during professional life.

3.3. Data Analysis (Step 3)

The collected Likert-type data were analyzed with non-parametric tests in the data analysis step. The use of non-parametric tests was most appropriate in this study since the intention was not to combine participants’ responses regarding survey items into a composite scale [83,84]. Non-parametric tests are also useful in eliminating the effects of the distribution-related assumptions made in parametric tests [85,86].
The data analysis step involved the use of the Statistical Package for Social Sciences (SPSS) 17.0 (i) to calculate the mean ranks of barriers against using cryptocurrencies in construction projects; (ii) to perform the Friedman and Wilcoxon tests [87] to determine whether the mean rank difference between barriers in each category is statistically significant; and (iii) to conduct the Mann–Whitney U test [88] to determine whether the respondents’ opinions changed because of their expertise, their knowledge of the basic principles of economics, and their experience with the use of cryptocurrencies. Since there were two groups to compare, the Mann–Whitney U test was used rather than the Kruskal–Wallis test, which is used to compare more than two groups [89].
The internal consistency of the collected data has to be assessed by using reliability analysis [90]. The Cronbach’s alpha (α) coefficient needs to be at least higher than 0.7, and higher than 0.9 indicates excellent reliability [91]. In this study, the Cronbach’s alpha coefficient of the 18 barriers was calculated as 0.914, indicating an excellent internal consistency, which means that the data could be used for further investigations.
The mean rank of the 18 barriers were calculated to determine the respondents’ opinions about the impacts of these barriers. The mean rank scores also revealed the importance of each barrier with respect to the others in each barrier category.
The Friedman test was performed to analyze the data in each barrier category. The Friedman test is a non-parametric test that is performed to determine the differences between three or more variables. It aims to identify whether at least two groups or categories present populations with different median values [85,92]. The required sample size should be higher than 30 in the Friedman test [93]. If the p-value is lower than 0.05, it means that there are significant differences between the barriers at a significance level of 5% [94]. In case of significant differences, the Wilcoxon can be run to determine the difference between the most important barrier and the other barriers in the corresponding category. Using this test, the most important and statistically significant barrier(s) in each barrier category were identified.
Finally, the Mann–Whitney U test was used to investigate the differences between respondents’ opinions relative to several features, including respondents’ (i) knowledge of the basic principles of economics, (ii) experience in the use of cryptocurrencies, and (iii) profession. The Mann–Whitney U test is a non-parametric test used when the data is not normally distributed, and the two samples are unequal in size [95]. It can be used for hypothesis testing between two independent samples with ordinal data [96], hence determining whether two independent groups represent two populations with different median values [95,96,97]. If the p-value is equal to or smaller than a predetermined level of significance (e.g., 0.05), then the difference between the two groups is statistically significant [98]. This test has been used commonly in the literature for similar research questions [88,98,99,100].

4. Results

Cryptocurrencies have the potential to bring advantages to financial transactions between supply chain partners in construction projects as an alternative payment protocol. Additionally, the use of cryptocurrencies may affect the performance of suppliers in particular, whose productivity rely mostly on regular payments. By integrating blockchain-based smart contracts and a cryptocurrency-based payment protocol, the transparency and trust among the parties involved in the supply chain could be improved, which in turn may increase the value generated during the supply chain process. However, many challenges still exist hindering the adoption of cryptocurrencies in construction supply chain management. Hence, this study surveyed construction professionals’ opinions about 18 barriers against using cryptocurrencies as a payment protocol in construction supply chains. Statistical analyses were used to address (i) the most significant barriers and (ii) the opinion differences between respondents. Unveiling the most significant barriers could enable the development of strategies to minimize the concerns of project stakeholders about the use of cryptocurrencies. Furthermore, the opinion differences between construction professionals can also help construction companies to develop strategies to improve their human resource that can add competitive advantage to them in the sector. The following sub-sections provide the results of this study in terms of the most significant barriers and opinion differences.

4.1. Most Significant Barriers against Using Cryptocurrencies

The findings of the statistical analyses are presented in Table 3. Based on the Friedman tests performed for each barrier category (the three columns before the last column), statistically significant differences were observed in the ranking of barriers. It can therefore be stated that some of the barriers are more significant than others. To investigate the differences of the barriers in each category, the Wilcoxon test was conducted, and the results can also be seen in Table 3 (last column). The findings show that the most significant barriers in each category are:
  • In the Technical Barriers category: a lack of technical knowledge about cryptocurrencies (Tc1).
  • In the Trust-Related Barriers category: security gaps due to vulnerable wallet passwords and malicious software (Tr1) and personal information required by cryptocurrency systems (Tr3).
  • In the Market-Related Barriers category: fluctuations in the value of the cryptocurrency (Mr1) and limited market opportunities (Mr2).
  • In the Regulatory Barriers category: no assurance of permanent use of cryptocurrencies in the long run (Rg1) and government actions limiting or possibly forbidding the use of cryptocurrencies (Rg2).

4.2. Differences in Respondents’ Opinions about the Barriers against Using Cryptocurrencies

The differences in respondents’ opinions about the barriers against using cryptocurrencies were examined with respect to demographic features including (i) respondents’ knowledge of the basic principles of economics (yes or no), (ii) respondents’ experience in cryptocurrency use (yes or no), and (iii) respondents’ profession (architect/engineer or other).
The results of the Mann–Whitney U test with respect to the respondents’ knowledge about the basic principles of economics are shown in Table 4. The findings imply that respondents’ opinions were statistically different at a significance level of 0.05 in 10 of the identified barriers. The results showed that the respondents who are knowledgeable about the basic principles of economics tended to consider the following barriers as more serious than the others: changes in the protocols (Tc2), the irrevocable nature of the cryptocurrency system (Tc4), security gaps (Tr1), low maturity of cryptocurrency technologies (Tr2), ease with which fraudulent activities can be performed (Tr4), fluctuations in the value of the cryptocurrency (Mr1), doubts about the long-term viability of the cryptocurrency systems (Mr4), low adoption rates by SDMEs (Mr5), governmental actions possibly forbidding the use of cryptocurrencies (Rg2), and incompatibility of cryptocurrency systems with the current legal system (Rg3).
The differences between the opinions of respondents who have used cryptocurrencies previously and those who did not are shown in Table 5. The findings indicate that respondents’ opinions were statistically different at a significance level of 0.05 in 5 of the barriers. Professionals who had prior experience in the use of cryptocurrencies tended to consider four of these five barriers as the most serious: low maturity of current cryptocurrency technologies (Tr2), limited market opportunities (Mr2), low adoption rate by small and medium size enterprises (Mr5), government actions limiting or possibly prohibiting cryptocurrency systems (Rg2), whereas they considered use of cryptocurrency in illegal activities (Rg4) to be less impactful.
It was reported in the literature that the respondents’ professional background could also impact the respondents’ opinions about the barriers against using cryptocurrencies in construction supply chain management. The results of the Mann–Whitney U test with respect to respondents’ professions are illustrated in Table 6. The findings show that respondents who were engineers or architects considered the following four barriers to be less serious when compared to non-engineers or non-architects: lack of technical knowledge (Tc1), possible changes in protocols (Tc2), low maturity of current cryptocurrency technologies (Tr2), and low adoption by SMEs (Mr5). The differences in the respondents’ opinions about these four barriers were statistically significant at 0.05 level.
A summary of the differences between the respondents’ opinions with respect to three demographic features is illustrated in Table 7. The findings show that integration deficiencies with other services (Tc3), difficulties in converting blockchain-based cryptocurrencies to traditional currencies (Tc5), requirement of personal information (Tr3), risky currency compared to other currencies (Mr3), and not providing guarantee for permanent use (Rg1) were not considered by any participant groups considered in this part of the study to be more important barriers than others. It is not surprising that none of these barriers were found among the top barriers according to the mean rank scores (Table 3). Table 7 also shows that the opinions of respondents who are knowledgeable about the basic principles of economics, who had prior experience in the use of cryptocurrencies, and who are not engineers or architects (such as finance experts, accountants, and information technology professionals) had similar views about low maturity of current cryptocurrency technologies (Tr2) and low adoption rate by SMEs (Mr5). It is not surprising to see that engineers and architects are not as informed about blockchain technologies and cryptocurrencies as are finance, accounting, and IT professionals.

5. Discussion

This study evaluates the barriers against adopting cryptocurrencies in construction supply chains as an alternative payment structure. The findings of this study highlighted the lack of technical knowledge, security related issues, price fluctuations, market opportunities, governmental actions, and legal procedures.
Past studies mostly focus on the general use of blockchain technologies. For instance, Cheng et al. [101] performed a systematic literature review to identify the benefits and challenges of blockchain technologies and concluded that information security and trust are among the major challenges faced by stakeholders in implementing blockchain in construction supply chain management. Overall, the researchers identified significant challenges in construction such as data security, scalability, technical integration, expertise, installation cost, organizational complexity, characteristic of the construction, regulation issues, and social acceptance. A similar study was also performed by Xu et al. [21] who found that a lack of IT infrastructure, uncertainty in legal regulations, and project complexities are the root barriers in the architecture, engineering, and construction (AEC) industry. Nawari and Ravindran [50] investigated the potentials and limitations of using blockchain technology in the built environment with a particular focus on integrating blockchain with BIM. The researchers found that inadequate education at company level, privacy, risk allocation, and responsibility assignment were the significant barriers. Nanayakkara et al. [51] performed a literature survey to compare blockchain technology with existing information systems in construction supply chains and highlighted that blockchain and smart contracts can present limitations related to recoverability, scalability, modifiability, maturity, complexity, and developability compared to conventional approaches. Tezel et al. [59] examined the applications of blockchain-based models in construction supply chains through focus group discussion sessions. Overall, the feedback provided by the participants highlighted that cultural resistance (as opposed to automated payment), issues related to fluctuations of the value of tokens, and necessity of integrating clients’ accounting, ID systems and existing contracts were elaborated as significant issues when implementing blockchain. In addition to the studies directly related to the AEC industry, Ghosh et al. [102] examined the security of cryptocurrencies and highlighted several challenges in its adoption such as usability, security, privacy, versioning, size, wasted resource, latency, and throughput.

5.1. Evaluation of the Barriers against Using Cryptocurrencies

The following paragraphs discuss the most significant barriers in the barrier categories defined earlier in this paper, namely technical, trust-related, market-related, and regulatory barriers.
Technical Barriers Category: It was highlighted by Chowdhury et al. [103] that professionals’ lack of understanding of cryptocurrencies is one of the most significant barriers for technology adoption in construction projects. It is also noted by Qammaz and AlMaian [104] that personnel’s inadequate technical knowledge could lead to ineffective risk management practices, which is particularly important when new procedures are adopted [105]. These assertions are supported by the findings in this study that show that lack of technical knowledge about cryptocurrencies (Tc1) is indeed the most significant barrier in the Technical Barriers category. The construction industry is known to be a slow adopter of emerging technologies and tools [106]. With advances in digitalization and potential applications of blockchain technology in the industry, construction companies should employ staff who are familiar with contemporary developments and tools [107]. The know-how transferred to the organization by these employees can bring momentum in the adoption of several recent technologies including the use of cryptocurrencies as a payment protocol.
Trust-Related Barriers Category: The respondents evaluated security gaps due to wallet passwords and malicious software (Tr1) and personal information required by cryptocurrency systems (Tr3) as serious barriers against using cryptocurrencies in trust-related barriers, both barriers related to the security concerns of potential users. Despite the fact that the security of cryptocurrencies is considered to be very strong as it is based on a chain of cryptographic puzzles, there are still some security concerns reported by users who are uncomfortable because cryptocurrencies are fully digital currencies that have no physical existence [108]. Viruses, keystroke loggers, or malware could leave wallets unprotected [109]. Bushager et al. [110] examined the security and privacy of Bitcoin and found that hardware failure, software failure, self-induced events, and malicious events were the most frequent reasons for Bitcoin key loss. Although cryptocurrencies’ security, speed, and not requiring intermediaries can facilitate international transactions, the extent of fraudulent and criminal activities cannot be ignored, limiting cryptocurrencies’ widespread use [111]. In this respect, a cryptocurrency regulation is being developed in the U.S., which will prevent tax evasion, abate crime, and make cryptocurrencies a secure vehicle for investment [112]. In addition to the U.S., there are other crypto-friendly countries such as Canada considering crypto transactions as business income, Australia accepting cryptocurrencies for capital gains tax purposes, and El Salvador which is the only country that allows cryptocurrencies as legal tender [113]. These uncoordinated developments can limit cryptocurrencies’ use in international contracts. This is particularly important for construction projects since many construction companies are involved in several projects across the world and need speed, stability, and certainty in cross-border financial transactions [114].
Market-Related Barriers Category: The results of Wilcoxon tests also showed that fluctuations in the value of the cryptocurrency (Mr1) and limited market opportunities (Mr2) are the most significant market-related barriers. The regular occurrence of tremendous price fluctuations in the value of cryptocurrencies [115] is not rare. These serious fluctuations in the value of tokens are expected to complicate cryptocurrency use [59], to be a major barrier against transactions in cryptocurrencies, and to contribute to the limited use of cryptocurrencies in the construction supply chain. Speculative activities in the cryptocurrency market are particularly conducive to volatility and uncertainty, which in turn result in reducing the efficacy of cryptocurrencies [116]. It is likely that one of the reasons why construction professionals would hesitate using cryptocurrencies is to protect their company against fluctuations in the value of cryptocurrencies.
Regulatory Barriers Category: In the category investigating the regulatory barriers, no assurance of permanent use of cryptocurrencies in the long run (Rg1) and government actions limiting or possibly forbidding the use of cryptocurrencies (Rg2) were determined as the most significant barriers. Several restricting regulations over the use of cryptocurrencies were issued in different countries. For example, a crackdown on Bitcoin in China led to a sharp decline in the price of Bitcoin and other cryptocurrencies by as much as 30% [117], and the Central Bank of China announced all cryptocurrency transactions are illegal in the country [118]. In Turkey, according to a recent regulation, crypto assets cannot be used directly or indirectly for payments [119]. A recent report of the European Securities and Markets Authority (ESMA) [120] drew attention to the risks involved in crypto-asset investments since crypto-assets are characterized by extreme price volatility. The report also pointed out that most trading platforms are unregulated and are prone to manipulation and operational flaws. Such reports and restrictions can slow down or limit the adoption of cryptocurrencies in business transactions as an alternative payment method, despite the sizeable reduction of transaction costs particularly in international transactions. The decentralized nature of the technology compels central banks and governments to issue restrictive national and international regulations. Therefore, a robust legal framework, can provide market confidence and new opportunities to diversify a company’s portfolio [116]. An appropriate legal framework can provide a reliable financial environment for stakeholders and endorse the use of cryptocurrencies as an alternative solution to chronic payment problems in the construction supply chain.
Overall, cryptocurrencies are digital currencies based on blockchain technology and can contribute to digitalization in several processes. For instance, having change, time, and fraud-resistant records of data with the help of blockchain technology can address some of the adoption issues of building information modeling (BIM). The use of cryptocurrency in the procurement system increases the security of transactions and payments made by a company and supports the implementation of BIM in a more confident way [19]. The integrated use of cryptocurrencies with smart contracts ensures the formation of an unchallengeable record of cost and payment, which can be implemented in 5D BIM that includes cost estimation and analysis [121]. Transactions can be recorded and tracked by project stakeholders in a distributed manner, improving traceability and trust within the project environment. However, a construction supply chain that is digitalized with cryptocurrencies requires that the many stakeholders in the supply chain (i.e., contractors and their material dealers) adopt cryptocurrencies to perform construction activities [23]. Therefore, inter-stakeholder solutions need to be sought in addition to mutually agreeable regulations for a sustainable and reliable cryptocurrency-based payment mechanism.

5.2. Opinion Differences between Respondents

Considering that blockchain technology is interlinked with basic economic systems [122], it is not surprising to see that respondents who were exposed to basic economic principles through economics courses/training would expect these 10 barriers to be taken seriously by professionals in the construction industry. Presthus and O’Malley [123] performed a survey on Bitcoin adoption and found that people mostly used cryptocurrencies due to technological curiosity. Thus, construction professionals who wish to experiment with cryptocurrency systems, should acquire a good knowledge of the basic principles of economics and should be prepared to overcome the 10 barriers identified in this analysis.
Considering the respondents’ strong opinions about the low maturity of cryptocurrency systems, the limited market opportunities, the low adoption rates by small and medium size companies, and the uncertain future of cryptocurrency systems, professionals who have been exposed to the use of cryptocurrencies in the past might consider cryptocurrencies to be more suitable for personal and largely speculative investments rather than professional use risking the survival and growth of a company just as Penzes et al. [11] state. Their fear of governmental actions limiting or possibly prohibiting cryptocurrencies may very well have developed during their exposure to the cryptocurrency environment in the past, as were their opinions about the market conditions, the maturity and uncertainty associated with cryptocurrencies, and the lack of legal protections. It is somewhat intriguing that respondents with prior experience with cryptocurrencies minimized the dangers of using this currency system for illegal activities. Nevertheless, an opinion informed with cryptocurrency practices has value and should receive special attention by construction professionals who are planning to be future users of cryptocurrencies.
The results might indicate that construction professionals, who are generally engineers or architects, can underestimate the potential impact of many barriers against using cryptocurrencies very much like they underestimate the importance of technical advances as evidenced in Yaşar et al.’s [124] work. On the other hand, it should be noted that in an early study, Zhou et al. [74] found that payments made with a cryptocurrency protocol in small and medium size enterprises do create transaction difficulties for these companies’ management.

6. Managerial Insights

Cryptocurrencies were introduced as a new electronic payment protocol based on blockchain technology, which allows the exchange of assets digitally in a decentralized system with lower transaction costs and improved traceability of the entire transaction history. Their emergence, development, and proliferation are a typical part of Industry 4.0, supporting industrial connectivity and smart automation. These features pledge several advantages, yet there are still challenges in their adoption as an alternative to conventional payment methods.
Inherent in their nature, construction projects involve different types of risky processes associated with many stakeholders that require proper management and coordination practices. Supply chain management is one of the important processes in the life cycle of especially building construction projects, which mostly operate on conventional approaches. As a slow adopter of recent technologies, construction professionals mostly prefer using well established methods and technologies rather than relying on novel and innovative practices. Employing professionals who can evaluate and appreciate the pros and cons of the adoption of recent technologies such as cryptocurrencies as an alternative payment protocol in supply chain management would be useful. As digitalization of many processes is becoming widespread in the construction industry, employing such qualified professionals would provide a competitive advantage to companies operating in the construction market. On the other hand, the legal challenges, that potential users of cryptocurrencies may face require proper regulations to provide confidence and stability to the potential adopters of this technology. This becomes even more critical in international transactions that are very common in the building construction supply chain. Overcoming at least the most important barriers identified in this study may persuade construction professionals to use cryptocurrencies in supply chain management and to integrate this advanced payment process with other recent technologies such as smart contracts and BIM.
Further investigations related to the professionals’ opinions revealed the following results:
  • The respondents who are not familiar with the basic principles of economic theory and practice are less concerned about the use of cryptocurrencies. The respondents who are familiar with the basic principles of economics, tend to be concerned about the potential barriers, such as changes in cryptocurrency protocols, security gaps caused by vulnerable wallet passwords and malicious software, government actions that could limit and possibly prohibit the use of cryptocurrencies, and the incompatibility of cryptocurrency systems with the current legal system. Therefore, employers’, consulting economists’, and legal experts’ fundamental knowledge of economics can be instrumental in acknowledging the pros and cons of adopting cryptocurrencies in construction supply chain management and in mitigating the adverse implications of cryptocurrencies in transactional activities in the construction industry.
  • Respondents who had experienced using cryptocurrencies felt more threatened by market-related and regulatory concerns than respondents with no prior exposure to cryptocurrencies. This can be related to the awareness of these respondents about the developments in the economic and legal domains. Since rapid value changes and severe fluctuations are common in the cryptocurrency market, central banks and governments issue regulations and the legislature enacts laws frequently, which might affect the implementations in the transactional processes. Professionals who are familiar with cryptocurrencies and who follow the associated national and international developments can be useful assets in a construction organization, if such a payment protocol is adopted in the supply chain processes.
  • Respondents in the engineering and architecture professions were less concerned about the use of cryptocurrencies than other professionals. This tendency may hinder the development of adequate risk mitigation measures to minimize the potential concerns highlighted by others. Advances in technology are inevitable and continuous and may have different impacts depending on the activity, the industry, and the economic environment. Construction professionals generally tend to focus on technical issues and try to resolve them using conventional methods and tools. On the other hand, modern technologies that are recently developed are finding their ways into construction projects. Analyzing the issues encountered in construction supply chains is one of the most investigated topics in the construction management literature. Construction professionals’ exposure to non-technical aspects of construction projects, secure transaction processes between contractors and suppliers, stable market value of cryptocurrencies and demand for construction, and a good understanding of government policies concerning the transactions between contractors and suppliers could contribute to improved construction supply chain processes.

7. Conclusions

Construction companies and suppliers are frequently faced with payment-related issues, which adversely impact the performance of the supply chain especially in building construction. Flawless material delivery and prompt payment are important to sustain efficient supply chain practices, and yet delayed payment or non-payment is a cultural reality in the construction industry. This study aimed to explore the challenges and barriers against using cryptocurrencies as an emerging payment protocol in construction supply chain management. The most significant barriers in each category were identified through a literature review and refined in a focus group discussion. Then, the Friedman and Wilcoxon tests were performed to observe the differences in the ranking of the categories and the barriers. Finally, the Mann–Whitney U test was performed to examine and understand the differences in the respondents’ opinions with respect to their expertise, their knowledge about the basic principles of economics, and their experience in the use of cryptocurrencies.
The findings imply that the lack of technical knowledge about cryptocurrencies, fluctuations in the value of cryptocurrencies, limited market opportunities, security gaps due to vulnerable wallet passwords and malicious software, requiring users to provide identifiable information, no assurance of permanent use of cryptocurrencies in the long run, and government actions limiting or forbidding the use of cryptocurrencies were the most important barriers against using cryptocurrencies in construction supply chain management. This study also investigated the differences in construction professionals’ opinions based on the characteristics of the respondents. For example, significant differences were detected between respondents with or without solid knowledge about the basic principles of economics; between respondents with or without experience in the use of cryptocurrencies; and between respondents who are engineers/architects or practicing other professions.
Overall, this study involves an exploratory investigation related to the adoption of cryptocurrencies in supply chain processes in construction projects. Identifying and understanding the potential barriers against using cryptocurrencies in supply chain management may make it easier to overcome these barriers and encourage construction professionals to consider adopting cryptocurrencies as an alternative solution to chronic payment problems encountered in the construction supply chain of especially building construction projects. Being one of the first attempts in the literature to explore the adoption of cryptocurrencies in construction supply chains, this study opens the way to using cryptocurrencies in financial transactions between contractors and suppliers in construction projects. Further studies can be conducted to find out the ways of integrating cryptocurrencies in contracts and evaluating stakeholders’ perspectives.

Author Contributions

Conceptualization, A.P.G. and M.I.G.; methodology, A.P.G. and K.K.; software, A.P.G. and K.K.; formal analysis, A.P.G. and K.K; investigation, A.P.G. and M.I.G.; resources, A.P.G. and M.I.G.; data curation, M.I.G. and K.K.; writing—original draft preparation, K.K. and M.I.G.; writing—review and editing, A.P.G. and D.A.; supervision, A.P.G. and D.A. All authors have read and agreed to the published version of the manuscript.

Funding

The work described in this paper was supported by the Coordinatorship of Scientific Research Projects of the Yildiz Technical University (Project ID: FBA-2021-4178).

Institutional Review Board Statement

Not applicable.

Informed Consent Statement

Not applicable.

Data Availability Statement

Data is contained within the article.

Acknowledgments

The work described in this paper was supported by the Coordinatorship of Scientific Research Projects of the Yildiz Technical University (Project ID: FBA-2021-4178). The authors would like to acknowledge that this paper is submitted in partial fulfilment of the requirements for PhD degree at Yildiz Technical University.

Conflicts of Interest

The authors declare no conflict of interest.

References

  1. Ramachandra, T.; Rotimi, J.O.B. Causes of payment problems in the New Zealand construction industry. Constr. Econ. Build. 2015, 15, 43–55. [Google Scholar] [CrossRef] [Green Version]
  2. Ramachandra, T. Exploring Feasible Solutions to Payment Problems in the Construction Industry in New Zealand. Ph.D. Thesis, Auckland University of Technology, Auckland, New Zealand, 2013. [Google Scholar]
  3. Abidin, N.A.Z.; Ingirige, B. The dynamics of vulnerabilities and capabilities in improving resilience within Malaysian construction supply chain. Constr. Innov. 2018, 18, 412–432. [Google Scholar] [CrossRef] [Green Version]
  4. Mithun, S.A.; Kumar, S.P.; Chowdhury, P.; Agarwal, R.; Fathollahi-Fard, A.M.; Jose, C.C.J.; Luthra, S. Modelling of supply chain disruption analytics using an integrated approach: An emerging economy example. Expert Syst. Appl. 2021, 173, 114690. [Google Scholar] [CrossRef]
  5. Chen, H.L.; Chen, W.T. Clarifying the behavioral patterns of contractor supply chain payment conditions. Int. J. Proj. Manag. 2005, 23, 463–473. [Google Scholar] [CrossRef]
  6. Latham, M. Trust and Money: Interim Report of the Joint Government/Industry Review of Procurement and Contractual Arrangements in the United Kingdom Construction Industry. In Joint Government/Industry Review of Procurement and Contractual Arrangements in the United Kingdom Construction Industry; Department of the Environment: London, UK, 1993. [Google Scholar]
  7. Hussain, S.; Zhu, F.; Ali, Z.; Aslam, H.D.; Hussain, A. Critical Delaying Factors: Public Sector Building Projects in Gilgit-Baltistan, Pakistan. Buildings 2018, 8, 6. [Google Scholar] [CrossRef] [Green Version]
  8. Chen, Y.; Zhu, L.; Hu, Z.; Chen, S.; Zheng, X. Risk Propagation in Multilayer Heterogeneous Network of Coupled System of Large Engineering Project. J. Manag. Eng. 2022, 38, 04022003. [Google Scholar] [CrossRef]
  9. Abdul Nabi, M.; El-adaway, I.H. Understanding Disputes in Modular Construction Projects: Key Common Causes and Their Associations. J. Constr. Eng. Manag. 2022, 148, 04021184. [Google Scholar] [CrossRef]
  10. Stamatiou, D.R.I.; Kirytopoulos, K.A.; Ponis, S.T.; Gayialis, S.; Tatsiopoulos, I. A process reference model for claims management in construction supply chains: The contractors’ perspective. Int. J. Constr. Manag. 2019, 19, 382–400. [Google Scholar] [CrossRef]
  11. Penzes, B.; Kirkup, A.; Gage, C.; Dravai, T.; Colmer, M. Blockchain Technology in the Construction Industry-Digital Transformation for High Productivity; Institution of Civil Engineers (ICE): London, UK, 2018. [Google Scholar]
  12. Hansen, S.; Rostiyanti, S.F.; Rif’at, A. Causes, Effects, and Mitigations Framework of Contract Change Orders: Lessons Learned from GBK Aquatic Stadium Project. J. Leg. Aff. Disput. Resolut. Eng. Constr. 2020, 12, 05019008. [Google Scholar] [CrossRef]
  13. Peters, E.; Subar, K.; Martin, H. Late Payment and Nonpayment within the Construction Industry: Causes, Effects, and Solutions. J. Leg. Aff. Disput. Resolut. Eng. Constr. 2019, 11, 04519013. [Google Scholar] [CrossRef]
  14. Wu, J.; Kumaraswamy, M.M.; Soo, G. Regulative Measures Addressing Payment Problems in the Construction Industry: A Calculative Understanding of Their Potential Outcomes Based on Gametric Models. J. Constr. Eng. Manag. 2011, 137, 566–573. [Google Scholar] [CrossRef]
  15. Motawa, I.; Kaka, A. Modelling payment mechanisms for supply chain in construction. Eng. Constr. Archit. Manag. 2009, 16, 325–336. [Google Scholar] [CrossRef]
  16. Tran, H.; Carmichael, D.G. The likelihood of subcontractor payment: Downstream progression via the owner and contractor. J. Financ. Manag. Prop. Constr. 2012, 17, 135–152. [Google Scholar] [CrossRef]
  17. Andalib, R.; Hoseini, A.; Gatmiri, B. A stochastic model of cash flow forecasting considering delays in owners’ payments. Constr. Manag. Econ. 2018, 36, 545–564. [Google Scholar] [CrossRef]
  18. Chong, H.Y.; Diamantopoulos, A. Integrating advanced technologies to uphold security of payment: Data flow diagram. Autom. Constr. 2020, 114, 103158. [Google Scholar] [CrossRef]
  19. Sigalov, K.; Ye, X.; König, M.; Hagedorn, P.; Blum, F.; Severin, B.; Hettmer, M.; Hückinghaus, P.; Wölkerling, J.; Groß, D. Automated Payment and Contract Management in the Construction Industry by Integrating Building Information Modeling and Blockchain-Based Smart Contracts. Appl. Sci. 2021, 11, 7653. [Google Scholar] [CrossRef]
  20. Ahmadisheykhsarmast, S.; Sonmez, R. A smart contract system for security of payment of construction contracts. Autom. Constr. 2020, 120, 103401. [Google Scholar] [CrossRef]
  21. Xu, Y.; Chong, H.Y.; Chi, M. Modelling the blockchain adoption barriers in the AEC industry. Eng. Constr. Archit. Manag. 2021, 1–29. [Google Scholar] [CrossRef]
  22. Darabseh, M.; Martins, J.P. Risks and opportunities for reforming construction with blockchain: Bibliometric study. Civ. Eng. J. 2020, 6, 1204–1217. [Google Scholar] [CrossRef]
  23. Kiu, M.S.; Chia, F.C.; Wong, P.F. Exploring the potentials of blockchain application in construction industry: A systematic review. Int. J. Constr. Manag. 2020, 1–10. [Google Scholar] [CrossRef]
  24. Gurgun, A.P.; Koc, K. Administrative risks challenging the adoption of smart contracts in construction projects. Eng. Constr. Archit. Manag. 2021, 29, 989–1015. [Google Scholar] [CrossRef]
  25. Nanayakkara, S.; Perera, S.; Senaratne, S. Stakeholders’ Perspective on Blockchain and Smart Contracts Solutions for Construction Supply Chains. In Proceedings of the CIB World Building Congress, Hong Kong, China, 17–21 June 2019. [Google Scholar]
  26. Yazdani, M.; Kabirifar, K.; Fathollahi-Fard, A.M.; Mojtahedi, M. Production scheduling of off-site prefabricated construction components considering sequence dependent due dates. Environ. Sci. Pollut. Res. 2021, 1–17. [Google Scholar] [CrossRef]
  27. Abdul Kadir, M.R.; Lee, W.P.; Jaafar, M.S.; Sapuan, S.M.; Ali, A.A.A. Factors affecting construction labour productivity for Malaysian residential projects. Struct. Surv. 2005, 23, 42–54. [Google Scholar] [CrossRef]
  28. Priyadarshani, G.H.K. Cost Impact of “Security of Payment Act” to the Si Lankan Construction Supply Chain. Ph.D. Thesis, University of Moratuwa, Moratuwa, Sri Lanka, 2018. [Google Scholar]
  29. Supardi, A.; Adnan, H.; Mohammad, M.F. Sub-Contractors’ Readiness on the Malaysian Security of Payment Legislation in Construction industry. In Proceedings of the International Conference on Construction and Project Management, Kansas City, MS, USA, 23–25 March 2011; pp. 248–252. [Google Scholar]
  30. Chen, H.L. Empirical behavioral analysis of project contractors’ supply-chain payment terms. Supply Chain Manag. An Int. J. 2012, 17, 277–289. [Google Scholar] [CrossRef]
  31. Pettigrew, R. The legal and contractual background. In Payment under Construction Contracts Legislation; Thomas Telford: London, UK, 2005. [Google Scholar]
  32. Bayley, G. Construction adjudication in New Zealand under the Construction Contracts Act 2002. In Proceedings of the 9th LEADR International ADR Conference, Wellington, New Zealand, 21 September 2007; pp. 19–21. [Google Scholar]
  33. Chen, H.L. An empirical examination of project contractors’ supply-chain cash flow performance and owners’ payment patterns. Int. J. Proj. Manag. 2011, 29, 604–614. [Google Scholar] [CrossRef]
  34. Loosemore, M.; Lim, B. Inter-organizational unfairness in the construction industry. Constr. Manag. Econ. 2015, 33, 310–326. [Google Scholar] [CrossRef]
  35. Martin, L.; Benson, L. Relationship quality in construction projects: A subcontractor perspective of principal contractor relationships. Int. J. Proj. Manag. 2021, 39, 633–645. [Google Scholar] [CrossRef]
  36. Koc, K.; Gurgun, A.P. Stakeholder-Associated Life Cycle Risks in Construction Supply Chain. J. Manag. Eng. 2021, 37, 04020107. [Google Scholar] [CrossRef]
  37. Morrison, S.; Trushell, I. Payment for offsite goods and materials: The Scottish perspective. Constr. Manag. Econ. 2016, 34, 679–687. [Google Scholar] [CrossRef] [Green Version]
  38. Riazi, S.R.M.; Ismail, R.; Nawi, M.N.M.; Shaharizan, M.F.; Yunus, R.; Alhawatmeh, O.S. Payment issues in industrialized building system (IBS) projects in Malaysia: Towards a better approach. Int. J. Supply Chain Manag. 2019, 8, 644–650. [Google Scholar]
  39. Mandičák, T.; Mésároš, P.; Spišáková, M. Impact of Information and Communication Technology on Sustainable Supply Chain and Cost Reducing of Waste Management in Slovak Construction. Sustainability 2021, 13, 7966. [Google Scholar] [CrossRef]
  40. Liu, K.S.; Lin, M.H. Performance Assessment on the Application of Artificial Intelligence to Sustainable Supply Chain Management in the Construction Material Industry. Sustainability 2021, 13, 12767. [Google Scholar] [CrossRef]
  41. RezaHoseini, A.; Noori, S.; Ghannadpour, S.F. Integrated scheduling of suppliers and multi-project activities for green construction supply chains under uncertainty. Autom. Constr. 2021, 122, 103485. [Google Scholar] [CrossRef]
  42. Ahmadi, H.B.; Lo, H.W.; Gupta, H.; Kusi-Sarpong, S.; Liou, J.J.H. An integrated model for selecting suppliers on the basis of sustainability innovation. J. Clean. Prod. 2020, 277, 123261. [Google Scholar] [CrossRef]
  43. Parkouhi, S.V.; Safaei Ghadikolaei, A. A resilience approach for supplier selection: Using Fuzzy Analytic Network Process and grey VIKOR techniques. J. Clean. Prod. 2017, 161, 431–451. [Google Scholar] [CrossRef]
  44. Shahsavar, M.M.; Akrami, M.; Gheibi, M.; Kavianpour, B.; Fathollahi-Fard, A.M.; Behzadian, K. Constructing a smart framework for supplying the biogas energy in green buildings using an integration of response surface methodology, artificial intelligence and petri net modelling. Energy Convers. Manag. 2021, 248, 114794. [Google Scholar] [CrossRef]
  45. Bhattacharya, S.; Chatterjee, A. Digital project driven supply chains: A new paradigm. Supply Chain Manag. 2021, 2, 283–294. [Google Scholar] [CrossRef]
  46. Hamledari, H.; Fischer, M. Measuring the impact of blockchain and smart contracts on construction supply chain visibility. Adv. Eng. Informatics 2021, 50, 101444. [Google Scholar] [CrossRef]
  47. Lee, D.; Lee, S. Digital Twin for Supply Chain Coordination in Modular Construction. Appl. Sci. 2021, 11, 5909. [Google Scholar] [CrossRef]
  48. Li, J.; Kassem, M. Informing Implementation of Distributed Ledger Technology (DLT) in Construction: Interviews with Industry and Academia. In Proceedings of the 36th International Conference of CIB W78, Newcastle, UK, 18–20 October 2019; pp. 169–178. [Google Scholar]
  49. Li, J.; Greenwood, D.; Kassem, M. Blockchain in the built environment and construction industry: A systematic review, conceptual models and practical use cases. Autom. Constr. 2019, 102, 288–307. [Google Scholar] [CrossRef]
  50. Nawari, N.O.; Ravindran, S. Blockchain and the built environment: Potentials and limitations. J. Build. Eng. 2019, 25, 100832. [Google Scholar] [CrossRef]
  51. Nanayakkara, S.; Perera, S.; Senaratne, S.; Weerasuriya, G.T.; Bandara, H.M.N.D. Blockchain and Smart Contracts: A Solution for Payment Issues in Construction Supply Chains. Informatics 2021, 8, 36. [Google Scholar] [CrossRef]
  52. Bakhtiarizadeh, E.; Shahzad, W.M.; Poshdar, M.; Khalfan, M.; Rotimi, J.O.B. Blockchain and Information Integration: Applications in New Zealand’s Prefabrication Supply Chain. Buildings 2021, 11, 608. [Google Scholar] [CrossRef]
  53. Bayramova, A.; Edwards, D.J.; Roberts, C. The Role of Blockchain Technology in Augmenting Supply Chain Resilience to Cybercrime. Buildings 2021, 11, 283. [Google Scholar] [CrossRef]
  54. Albayati, H.; Kim, S.K.; Rho, J.J. Accepting financial transactions using blockchain technology and cryptocurrency: A customer perspective approach. Technol. Soc. 2020, 62, 101320. [Google Scholar] [CrossRef]
  55. Corbet, S.; Lucey, B.; Urquhart, A.; Yarovaya, L. Cryptocurrencies as a financial asset: A systematic analysis. Int. Rev. Financ. Anal. 2019, 62, 182–199. [Google Scholar] [CrossRef] [Green Version]
  56. Yazdani, M.; Zarate, P.; Coulibaly, A.; Zavadskas, E.K. A group decision making support system in logistics and supply chain management. Expert Syst. Appl. 2017, 88, 376–392. [Google Scholar] [CrossRef] [Green Version]
  57. Moosavi, J.; Naeni, L.M.; Fathollahi-Fard, A.M.; Fiore, U. Blockchain in supply chain management: A review, bibliometric, and network analysis. Environ. Sci. Pollut. Res. 2021, 1–15. [Google Scholar] [CrossRef]
  58. Das, M.; Luo, H.; Cheng, J.C.P. Securing interim payments in construction projects through a blockchain-based framework. Autom. Constr. 2020, 118, 103284. [Google Scholar] [CrossRef]
  59. Tezel, A.; Febrero, P.; Papadonikolaki, E.; Yitmen, I. Insights into Blockchain Implementation in Construction: Models for Supply Chain Management. J. Manag. Eng. 2021, 37, 1–19. [Google Scholar] [CrossRef]
  60. Hamledari, H.; Fischer, M. The application of blockchain-based crypto assets for integrating the physical and financial supply chains in the construction & engineering industry. Autom. Constr. 2021, 127, 103711. [Google Scholar] [CrossRef]
  61. Dakhli, Z.; Lafhaj, Z.; Mossman, A. The Potential of Blockchain in Building Construction. Buildings 2019, 9, 77. [Google Scholar] [CrossRef] [Green Version]
  62. Elghaish, F.; Abrishami, S.; Hosseini, M.R. Integrated project delivery with blockchain: An automated financial system. Autom. Constr. 2020, 114, 103182. [Google Scholar] [CrossRef]
  63. Chileshe, N.; Rameezdeen, R.; Hosseini, M.R. Barriers to implementing reverse logistics in South Australian construction organisations. Supply Chain Manag. An. Int. J. 2015, 20, 179–204. [Google Scholar] [CrossRef]
  64. Ajayi, S.O.; Oyedele, L.O. Policy imperatives for diverting construction waste from landfill: Experts’ recommendations for UK policy expansion. J. Clean. Prod. 2017, 147, 57–65. [Google Scholar] [CrossRef] [Green Version]
  65. Al Yahya, M.; Skitmore, M.; Bridge, A.; Nepal, M.; Cattell, D. e-Tendering readiness in construction: The posterior model. Constr. Innov. 2018, 18, 183–205. [Google Scholar] [CrossRef]
  66. Perera, S.; Nanayakkara, S.; Rodrigo, M.N.N.; Senaratne, S.; Weinand, R. Blockchain technology: Is it hype or real in the construction industry? J. Ind. Inf. Integr. 2020, 17, 100125. [Google Scholar] [CrossRef]
  67. Bentov, I.; Ji, Y.; Zhang, F.; Breidenbach, L.; Daian, P.; Juels, A. Tesseract: Real-Time Cryptocurrency Exchange Using Trusted Hardware. In Proceedings of the 2019 ACM SIGSAC Conference on Computer and Communications Security, London, UK, 11–15 November 2019; pp. 1521–1538. [Google Scholar]
  68. Zeiringer, J.P.; Thalmann, S. Knowledge Risks in Digital Supply Chains: A Literature Review. In Proceedings of the 15th International Conference on Wirtschaftsinformatik, Potsdam, Germany, 4–6 March 2020. [Google Scholar]
  69. Novak, M. Crypto-friendliness: Understanding blockchain public policy. J. Entrep. Public Policy 2019, 9, 165–184. [Google Scholar] [CrossRef]
  70. Kristoufek, L.; Vosvrda, M. Cryptocurrencies market efficiency ranking: Not so straightforward. Phys. A Stat. Mech. Appl. 2019, 531, 120853. [Google Scholar] [CrossRef]
  71. Nakano, M.; Takahashi, A. A new investment method with AutoEncoder: Applications to crypto currencies. Expert Syst. Appl. 2020, 162, 113730. [Google Scholar] [CrossRef]
  72. Koblitz, N.; Menezes, A.J. Cryptocash, cryptocurrencies, and cryptocontracts. Des. Codes Cryptogr. 2016, 78, 87–102. [Google Scholar] [CrossRef]
  73. Conrad, C.; Custovic, A.; Ghysels, E. Long- and Short-Term Cryptocurrency Volatility Components: A GARCH-MIDAS Analysis. Risk Financ. Manag. 2018, 11, 23. [Google Scholar] [CrossRef]
  74. Zhou, X.; Wu, Q.; Qin, B.; Huang, X.; Liu, J. Distributed Bitcoin Account Management. In Proceedings of the IEEE Trustcom/BigDataSE/ISPA, Tianjin, China, 23–26 August 2016; pp. 105–112. [Google Scholar]
  75. Herbert, J.; Litchfield, A. A Novel Method for Decentralised Peer -to-Peer Software License Validation Using Cryptocurrency Blockchain Technology. In Proceedings of the 38th Australasian Computer Science Conference, Parramatta, Australia, 27–30 January 2015; pp. 27–35. [Google Scholar]
  76. Deng, R.; Benckendorff, P.; Gannaway, D. Learner engagement in MOOCs: Scale development and validation. Br. J. Educ. Technol. 2020, 51, 245–262. [Google Scholar] [CrossRef]
  77. Gupta, S.; Agrawal, R. Environmentally responsible consumption: Construct definition, scale development, and validation. Corp. Soc. Responsib. Environ. Manag. 2018, 25, 523–536. [Google Scholar] [CrossRef]
  78. Lytras, M.D.; Visvizi, A.; Chopdar, P.K.; Sarirete, A.; Alhalabi, W. Information Management in Smart Cities: Turning end users’ views into multi-item scale development, validation, and policy-making recommendations. Int. J. Inf. Manage. 2021, 56, 102146. [Google Scholar] [CrossRef]
  79. Cacciotti, G.; Hayton, J.C.; Mitchell, J.R.; Allen, D.G. Entrepreneurial fear of failure: Scale development and validation. J. Bus. Ventur. 2020, 35, 106041. [Google Scholar] [CrossRef]
  80. Li, X.; Du, J.; Long, H. Understanding the green development behavior and performance of industrial enterprises (Gdbp-ie): Scale development and validation. Int. J. Environ. Res. Public Health 2020, 17, 1716. [Google Scholar] [CrossRef] [Green Version]
  81. Covin, J.G.; Rigtering, J.P.C.; Hughes, M.; Kraus, S.; Cheng, C.F.; Bouncken, R.B. Individual and team entrepreneurial orientation: Scale development and configurations for success. J. Bus. Res. 2020, 112, 1–12. [Google Scholar] [CrossRef]
  82. Li, X.; Du, J.; Long, H. Mechanism for green development behavior and performance of industrial enterprises (Gdbp-ie) using partial least squares structural equation modeling (pls-sem). Int. J. Environ. Res. Public Health 2020, 17, 8450. [Google Scholar] [CrossRef]
  83. Boone, H.N.; Boone, D.A. Analyzing Likert Data. J. Extention 2012, 50, 1–5. [Google Scholar] [CrossRef]
  84. Turan, İ.; Şimşek, Ü.; Aslan, H. Eğitim Araştırmalarında Likert Ölçeği ve Likert-Tipi Soruların Kullanımı ve Analizi. Sak. Üniversitesi Eğitim Fakültesi Derg. 2015, 30, 186–203. [Google Scholar]
  85. Rigdon, E.E. Using the Friedman method of ranks for model comparison in structural equation modeling. Struct. Equ. Model. 1999, 6, 219–232. [Google Scholar] [CrossRef]
  86. Siegel, S.; Castellan, N.J. Nonparametric Statistics for the Behavioral Sciences; McGraw-Hill: New York, NY, USA, 1988. [Google Scholar]
  87. Larsen, J.K.; Shen, G.Q.; Lindhard, S.M.; Brunoe, T.D. Factors Affecting Schedule Delay, Cost Overrun, and Quality Level in Public Construction Projects. J. Manag. Eng. 2016, 32, 04015032. [Google Scholar] [CrossRef] [Green Version]
  88. Burke, R.D.; Parrish, K.; El Asmar, M. Environmental Product Declarations: Use in the Architectural and Engineering Design Process to Support Sustainable Construction. J. Constr. Eng. Manag. 2018, 144, 04018026. [Google Scholar] [CrossRef]
  89. Başakın, E.E.; Ekmekcioğlu, Ö.; Çıtakoğlu, H.; Özger, M. A new insight to the wind speed forecasting: Robust multi-stage ensemble soft computing approach based on pre-processing uncertainty assessment. Neural Comput. Appl. 2022, 34, 783–812. [Google Scholar] [CrossRef]
  90. Gunduz, M.; Elsherbeny, H.A. Operational Framework for Managing Construction-Contract Administration Practitioners’ Perspective through Modified Delphi Method. J. Constr. Eng. Manag. 2020, 146, 040191110. [Google Scholar] [CrossRef]
  91. Zhang, X. Concessionaire’s Financial Capability in Developing Build-Operate-Transfer Type Infrastructure Projects. J. Constr. Eng. Manag. 2005, 131, 1054–1064. [Google Scholar] [CrossRef]
  92. Derrac, J.; García, S.; Molina, D.; Herrera, F. A practical tutorial on the use of nonparametric statistical tests as a methodology for comparing evolutionary and swarm intelligence algorithms. Swarm Evol. Comput. 2011, 1, 3–18. [Google Scholar] [CrossRef]
  93. Green, S.B.; Salkind, N.J. Using SPSS for Windows and Macintosh: Analyzing and Understanding Data, 7th ed.; Pearson Prentice: Upper Saddle River, NJ, USA, 2014. [Google Scholar]
  94. Chaphalkar, N.B.; Iyer, K.C.; Patil, S.K. Prediction of outcome of construction dispute claims using multilayer perceptron neural network model. Int. J. Proj. Manag. 2015, 33, 1827–1835. [Google Scholar] [CrossRef]
  95. Sheskin, D.J. Handbook of Parametric and Nonparametric Statistical Procedures; Chapman and Hall/CRC Press: Boca Raton, FL, USA, 2007. [Google Scholar]
  96. Chan, A.P.C.; Yeung, J.F.Y.; Yu, C.C.P.; Wang, S.Q.; Ke, Y. Empirical study of risk assessment and allocation of public-private partnership projects in China. J. Manag. Eng. 2011, 27, 136–148. [Google Scholar] [CrossRef] [Green Version]
  97. Shi, Q.; Zuo, J.; Huang, R.; Huang, J.; Pullen, S. Identifying the critical factors for green construction-An empirical study in China. Habitat Int. 2013, 40, 1–8. [Google Scholar] [CrossRef]
  98. Lam, P.T.I.; Javed, A.A. Comparative study on the use of output specifications for Australian and U.K. PPP/PFI projects. J. Perform. Constr. Facil. 2015, 29, 04014061. [Google Scholar] [CrossRef]
  99. Artan Ilter, D.; Bakioglu, G. Modeling the Relationship between Risk and Dispute in Subcontractor Contracts. J. Leg. Aff. Disput. Resolut. Eng. Constr. 2018, 10, 04517022. [Google Scholar] [CrossRef]
  100. Abotaleb, I.S.; El-Adaway, I.H.; Ibrahim, M.W.; Hanna, A.S.; Russell, J.S. Causes, Early Warning Signs, and Impacts of Out-of-Sequence Construction: Expert-Based Survey Analysis. J. Manag. Eng. 2019, 35, 04019030. [Google Scholar] [CrossRef]
  101. Cheng, M.; Liu, G.; Xu, Y.; Chi, M. When Blockchain Meets the AEC Industry: Present Status, Benefits, Challenges, and Future Research Opportunities. Buildings 2021, 11, 340. [Google Scholar] [CrossRef]
  102. Ghosh, A.; Gupta, S.; Dua, A.; Kumar, N. Security of Cryptocurrencies in blockchain technology: State-of-art, challenges and future prospects. J. Netw. Comput. Appl. 2020, 163, 102635. [Google Scholar] [CrossRef]
  103. Chowdhury, T.; Adafin, J.; Wilkinson, S. Review of digital technologies to improve productivity of New Zealand construction industry. J. Inf. Technol. Constr. 2019, 24, 569–587. [Google Scholar] [CrossRef]
  104. Bu Qammaz, A.S.; AlMaian, R.Y. A critical success factors model for effective implementation of risk management process in the construction projects. J. Eng. Res. 2020, 8, 50–70. [Google Scholar] [CrossRef]
  105. Yusuwan, N.M.; Adnan, H.; Omar, A.F.; Jusoff, H.K. Clients’ Perspectives of Risk Management Practice in Malaysian Construction Industry. J. Polit. Law 2008, 1, 121–130. [Google Scholar] [CrossRef]
  106. Agarwal, R.; Chandrasekaran, S.; Sridhar, M. Imagining Construction’s Digital Future McKinsey Co. 2016. Available online: https://www.modularmd.com/hubfs/assets/reports/McKinsey-ImaginingConstructionsDigitalFuture.pdf (accessed on 15 February 2022).
  107. Peansupap, V.; Walker, D.H.T. Information communication technology (ICT) implementation constraints: A construction industry perspective. Eng. Constr. Archit. Manag. 2006, 13, 364–379. [Google Scholar] [CrossRef]
  108. Vyas, C.A.; Lunagaria, M. Security Concerns and Issues for Bitcoin. Int. J. Comput. Appl. 2014, 10–12. Available online: https://citeseerx.ist.psu.edu/viewdoc/download?doi=10.1.1.667.5197&rep=rep1&type=pdf (accessed on 15 February 2022).
  109. Drovak, J.; Shapiro, M.; Billings, J.; Taylor, C.; Falkenberg, E.; Schultz, S. Cryptocurrency Virtual Wallet System and Method. U.S. Patent US20150324789A1, 12 November 2015. [Google Scholar]
  110. Bushager, A.; Mirza, Z.; Alsalem, E. Bitcoin Security and Privacy: A Study of Users Experiences. In Proceedings of the Sustainability and Resilience Conference: Mitigating Risks and Emergency Planning, Davos, Switzerland, 23 November 2018; Volume 3, pp. 11–28. [Google Scholar]
  111. Sanz-Bas, D.; del Rosal, C.; Náñez Alonso, S.L.; Echarte Fernández, M.Á. Cryptocurrencies and Fraudulent Transactions: Risks, Practices, and Legislation for Their Prevention in Europe and Spain. Laws 2021, 10, 57. [Google Scholar] [CrossRef]
  112. Barker, M.R.; Bambara, J. United States: The U.S. Available online: https://www.mondaq.com/unitedstates/fin-tech/1111802/the-us-infrastructure-bill-and-cryptocurrency-regulation (accessed on 15 February 2022).
  113. Bajpai, P. Countries Where Bitcoin Is Legal and Illegal. Available online: https://www.investopedia.com/articles/forex/041515/countries-where-bitcoin-legal-illegal.asp (accessed on 15 February 2022).
  114. Lee, D.; Lee, S.H.; Masoud, N.; Krishnan, M.S.; Li, V.C. Integrated digital twin and blockchain framework to support accountable information sharing in construction projects. Autom. Constr. 2021, 127, 103688. [Google Scholar] [CrossRef]
  115. Li, T.R.; Chamrajnagar, A.S.; Fong, X.R.; Rizik, N.R.; Fu, F. Can local stress enhancement induce stability in fracture processes? Part I: Apparent stability. Front. Phys. 2019, 7, 1–8. [Google Scholar] [CrossRef]
  116. Antonakakis, N.; Chatziantoniou, I.; Gabauer, D. Cryptocurrency market contagion: Market uncertainty, market complexity, and dynamic portfolios. J. Int. Financ. Mark. Inst. Money 2019, 61, 37–51. [Google Scholar] [CrossRef] [Green Version]
  117. Yu, E.; Ping, C.K. China’s Latest Crackdown on Bitcoin, Other Cryptocurrencies Shakes Market. Available online: https://www.wsj.com/articles/chinas-latest-crackdown-on-bitcoin-other-cryptocurrencies-shakes-market-11621853002 (accessed on 15 February 2022).
  118. BBC China Declares All Crypto-Currency Transactions Illegal. Available online: https://www.bbc.com/news/technology-58678907 (accessed on 15 February 2022).
  119. Resmi Gazete Ödemelerde Kripto Varlıkların Kullanılmamasına Dair Yönetmelik. Available online: https://www.resmigazete.gov.tr/eskiler/2021/04/20210416-4.htm (accessed on 15 February 2022).
  120. European Securities and Markets Authority (ESMA) Report on Trends, Risks and Vulnerabilities. 2021. Available online: https://www.esma.europa.eu/press-news/esma-news/esma-sees-high-risk-investors-in-non-regulated-crypto-assets (accessed on 15 February 2022).
  121. Hamledari, H.; Fischer, M. Construction Payment Automation Using Blockchain-Enabled Smart Contracts and Reality Capture Technologies. Autom. Constr. 2020, 132, 103926. [Google Scholar] [CrossRef]
  122. Holotescu, C. Understanding Blockchain Opportunities and Challenges. In Proceedings of the 14th International Scientific Conference eLearning and Software for Education, Bucharest, Romania, 19–20 April 2018; pp. 275–284. [Google Scholar]
  123. Presthus, W.; O’Malley, N.O. Motivations and Barriers for End-User Adoption of Bitcoin as Digital Currency. Procedia Comput. Sci. 2017, 121, 89–97. [Google Scholar] [CrossRef]
  124. Yaşar, Ş.; Baker, D.; Robinson-Kurpius, S.; Krause, S.; Roberts, C. Development of a survey to assess K-12 teachers’ perceptions of engineers and familiarity with teaching design, engineering, and technology. J. Eng. Educ. 2006, 95, 205–216. [Google Scholar] [CrossRef]
Figure 1. Research design.
Figure 1. Research design.
Buildings 12 00357 g001
Figure 2. Research flow.
Figure 2. Research flow.
Buildings 12 00357 g002
Figure 3. Distribution of respondents’ professions.
Figure 3. Distribution of respondents’ professions.
Buildings 12 00357 g003
Table 1. Barriers affecting the use of cryptocurrency in construction supply chains.
Table 1. Barriers affecting the use of cryptocurrency in construction supply chains.
Barrier CategoryIDBarriers against Using CryptocurrenciesIDReferences
Technical barriersTcLack of technical knowledge about cryptocurrenciesTc1Priyadarshani [28]
Possible changes in cryptocurrency protocolsTc2Al Yahya [65]
Integration difficulties with other servicesTc3Nawari and Ravindran [50]
Irrevocable nature of cryptocurrency systemsTc4Perera et al. [66]
Difficulties in converting cryptocurrencies to traditional currencies Tc5Bentov et al. [67]
Trust-related barriersTrSecurity gaps due to vulnerable wallet passwords and malicious softwareTr1Zeiringer and Thalmann [68]
Low maturity of current cryptocurrency technologiesTr2Novak [69]
Personal information required by cryptocurrency systemsTr3Perera et al. [66]
Easy to commit fraudTr4Perera et al. [66]
Market-related barriersMrFluctuations in the value of the cryptocurrencyMr1Kristoufek and Vosvrda [70]
Limited market opportunitiesMr2Nakano and Takahashi [71]
Risky currency compared to traditional currenciesMr3Koblitz and Menezes [72]
Doubts about the long-term viability of cryptocurrency systemsMr4Conrad et al. [73]
Low adoption rate by SMEsMr5Zhou et al. [74]
Regulatory barriersRgNo assurance of permanent use of cryptocurrencies in the long runRg1Herbert and Litchfield [75]
Governmental actions limiting or possibly forbidding the use of cryptocurrenciesRg2Koblitz and Menezes [72]
Incompatibility of cryptocurrency systems with the current legal systemRg3Perera et al. [66]
Possible use of cryptocurrencies in illegal activitiesRg4Perera et al. [66]
Table 2. Profile of the respondents.
Table 2. Profile of the respondents.
Demographic CharacteristicsResponsesN%
GenderMale22579.23
Female5920.77
Age20–30207.04
30–4011841.55
40–508228.87
50 and higher6422.54
Education levelHigh school144.93
Bachelor16658.45
MSc8931.34
PhD155.28
Income level (Turkish Lira)2500 and lower51.76
2500–50004415.49
5000–10,0009433.10
10,000–15,0006221.83
15,000 and higher7927.82
Professional experience (years)0–5217.39
6–1511640.85
16–257727.11
26 and higher7024.65
Number of companies worked for0–212042.25
2–512042.25
5–9258.80
10 and more196.69
Approximate size of company (USD million)50 and lower10838.03
50–1004415.49
100–5006322.18
500 and higher6924.30
Number of times of online shopping per yearNever62.11
0–1103.52
1–33311.62
3–54515.85
5 and higher19066.90
Experience in use of cryptocurrency (years)Never21475.35
0–1 144.93
1–32910.21
3–5124.23
5 and higher155.28
Exposure to courses/training in economicsYes14952.46
No13547.54
Table 3. Results of the Friedman test.
Table 3. Results of the Friedman test.
Barrier CategoryBarrier against Using CryptocurrenciesIDBasic StatisticsFriedman TestWilcoxon Test
MeanSt. Dev.Mean RankChi-SquareDegree of Freedomp-Valuep-Value
Technical barriers 92.7240.000
* Lack of technical knowledge about cryptocurrenciesTc13.7111.0713.56 -
Possible changes in cryptocurrency protocolsTc23.3560.9422.99 0.000 **
Integration difficulties with other servicesTc33.3490.9222.96 0.000 **
Irrevocable nature of cryptocurrency systemsTc43.2960.9422.80 0.000 **
Difficulties in converting cryptocurrencies to traditional currencies Tc53.1941.0472.69 0.000 **
Trust-related barriers 26.0130.000
* Security gaps due to vulnerable wallet passwords and malicious softwareTr13.4580.9992.67 -
Low maturity of current cryptocurrency technologiesTr23.3240.9552.55 0.041 **
Personal information required by cryptocurrency systemsTr33.3311.0652.51 0.060
Easy to commit fraudTr43.1301.0332.27 0.000 **
Market-related barriers 58.8540.000
* Fluctuations in the value of the cryptocurrencyMr13.4891.0073.27 -
Limited market opportunitiesMr23.4720.9673.24 0.534
Risky currency compared to traditional currenciesMr33.3101.0653.02 0.001 **
Doubts about the long-term viability of cryptocurrency systemsMr43.1800.9582.76 0.000 **
Low adoption rate by SMEsMr53.0741.1272.70 0.000 **
Regulatory barriers 153.3630.000
* No assurance of permanent use of cryptocurrencies in the long runRg13.3940.9842.82 -
Government actions limiting or possibly forbidding the use of cryptocurrenciesRg23.3560.9822.72 0.419
Incompatibility of cryptocurrency systems with the current legal systemRg33.1510.9592.49 0.000 **
Possible use of cryptocurrencies in illegal activitiesRg42.6201.0681.97 0.000 **
* The most significant barriers in each category according to the mean rank. ** The most significant barriers are statistically more important than these barriers at 0.05 level.
Table 4. Results of Mann–Whitney U test based on respondents’ knowledge about the basic principles of economics.
Table 4. Results of Mann–Whitney U test based on respondents’ knowledge about the basic principles of economics.
Barrier CategoryBarrier Against Using Cryptocurrenciesp-ValueExposure to Courses/Training in EconomicsMean ScoreMean Rank
Technical barriersTc1—Lack of technical knowledge about cryptocurrencies0.2806Attended3.745147.21
Not attended3.674137.30
Tc2—Possible changes in cryptocurrency protocols0.0016 *Attended3.537156.11
Not attended3.156127.47
Tc3—Integration difficulties with other services0.0424Attended3.436151.29
Not attended3.252132.80
Tc4—Irrevocable nature of cryptocurrency systems0.0212 *Attended3.409152.33
Not attended3.170131.66
Tc5—Difficulties in converting cryptocurrencies to traditional currencies0.2354Attended3.248147.73
Not attended3.133136.73
Trust-related barriersTr1—Security gaps due to vulnerable wallet passwords and malicious software0.0083 *Attended3.611154.12
Not attended3.289129.68
Tr2—Low maturity of current cryptocurrency technologies0.0140 *Attended3.450153.11
Not attended3.185130.79
Tr3—Personal information required by cryptocurrency systems0.5534Attended3.356145.13
Not attended3.304139.60
Tr4—Easy to commit fraud0.0468 *Attended3.242151.18
Not attended3.007132.92
Market-related barriersMr1—Fluctuations in the value of the cryptocurrency0.0176 *Attended3.604152.95
Not attended3.363130.97
Mr2—Limited market opportunities0.0655Attended3.557150.56
Not attended3.378133.60
Mr3—Risky currency compared to traditional currencies0.2533Attended3.362147.56
Not attended3.252136.92
Mr4—Doubts about the long-term viability of cryptocurrency systems0.0465 *Attended3.289151.03
Not attended3.059133.09
Mr5—Low adoption rate by SMEs0.0353 *Attended3.201151.84
Not attended2.933132.19
Regulatory barriersRg1—No assurance of permanent use of cryptocurrencies in the long run0.1894Attended3.443148.27
Not attended3.341136.14
Rg2—Government actions limiting or possibly prohibiting the use of cryptocurrencies0.0002 *Attended3.530158.78
Not attended3.163124.53
Rg3—Incompatibility of cryptocurrency systems with the current legal system0.0008 *Attended3.322157.04
Not attended2.963126.46
Rg4—Possible use of cryptocurrencies in illegal activities0.1872Attended2.544136.66
Not attended2.704148.95
* Difference is statistically significant at 0.05 level.
Table 5. The results of Mann–Whitney U test based on respondents’ experience in the use of cryptocurrencies.
Table 5. The results of Mann–Whitney U test based on respondents’ experience in the use of cryptocurrencies.
Barrier CategoryBarrier Against Using Cryptocurrenciesp-ValueExperience in Cryptocurrency UseMean ScoreMean Rank
Technical barriersTc1—Lack of technical knowledge about cryptocurrencies0.0876Experienced3.886156.20
Inexperienced3.654138.02
Tc2—Possible changes in cryptocurrency protocols0.4708Experienced3.386148.23
Inexperienced3.346140.63
Tc3—Integration difficulties with other services0.6532Experienced3.271138.93
Inexperienced3.374143.67
Tc4—Irrevocable nature of cryptocurrency systems0.6032Experienced3.186138.43
Inexperienced3.332143.83
Tc5—Difficulties in converting cryptocurrencies to traditional currencies0.0555Experienced2.986127.00
Inexperienced3.262147.57
Trust-related barriersTr1—Security gaps due to vulnerable wallet passwords and malicious software0.2212Experienced3.543152.39
Inexperienced3.430139.27
Tr2—Low maturity of current cryptocurrency technologies0.0023 *Experienced3.657166.73
Inexperienced3.215134.58
Tr3—Personal information required by cryptocurrency systems0.0844Experienced3.100128.45
Inexperienced3.407147.10
Tr4—Easy to commit fraud0.3294Experienced3.029134.68
Inexperienced3.164145.06
Market-related barriersMr1—Fluctuations in the value of the cryptocurrency0.3861Experienced3.529149.51
Inexperienced3.477140.21
Mr2—Limited market opportunities0.0350 *Experienced3.643159.46
Inexperienced3.416136.95
Mr3—Risky currency compared to traditional currencies0.1674Experienced3.100131.27
Inexperienced3.379146.17
Mr4—Doubts about the long-term viability of cryptocurrency systems0.7582Experienced3.157140.08
Inexperienced3.187143.29
Mr5—Low adoption rate by SMEs0.0000 *Experienced3.786195.92
Inexperienced2.841125.03
Regulatory barriersRg1—No assurance of permanent use cryptocurrencies in the long run0.4397Experienced3.271136.26
Inexperienced3.435144.54
Rg2—Government actions limiting or possibly prohibiting the use of cryptocurrencies0.0379 *Experienced3.471159.21
Inexperienced3.318137.03
Rg3—Incompatibility of cryptocurrency systems with the current legal system0.0787Experienced3.214156.43
Inexperienced3.131137.94
Rg4—Possible use of cryptocurrencies in illegal activities0.0000 *Experienced2.186107.31
Inexperienced2.762154.01
* Difference is statistically significant at 0.05 level.
Table 6. Results of Mann–Whitney U test based on respondents’ profession.
Table 6. Results of Mann–Whitney U test based on respondents’ profession.
Barrier CategoryBarrier Against Using Cryptocurrenciesp-ValueProfessionMean ScoreMean Rank
Technical barriersTc1—Lack of technical knowledge about cryptocurrencies0.0053 *Architect/engineer3.570132.71
Other3.952159.20
Tc2—Possible changes in cryptocurrency protocols0.0147 *Architect/engineer3.246134.01
Other3.543156.97
Tc3—Integration difficulties with other services0.4441Architect/engineer3.302139.84
Other3.429147.04
Tc4—Irrevocable nature of cryptocurrency systems0.1533Architect/engineer3.240137.60
Other3.390150.85
Tc5—Difficulties in converting cryptocurrencies to traditional currencies0.6585Architect/engineer3.173140.93
Other3.229145.17
Trust-related barriersTr1—Security gaps due to vulnerable wallet passwords and malicious software0.2068Architect/engineer3.397138.03
Other3.562150.12
Tr2—Low maturity of current cryptocurrency technologies0.0032 *Architect/engineer3.207132.27
Other3.524159.95
Tr3—Personal information required by cryptocurrency systems0.2962Architect/engineer3.279138.77
Other3.419148.85
Tr4—Easy to commit fraud0.1049Architect/engineer3.045136.80
Other3.276152.21
Market-related barriersMr1—Fluctuations in the value of the cryptocurrency0.7892Architect/engineer3.464141.55
Other3.533144.11
Mr2—Limited market opportunities0.8978Architect/engineer3.464142.05
Other3.486143.27
Mr3—Risky currency compared to traditional currencies0.8643Architect/engineer3.296141.89
Other3.333143.54
Mr4—Doubts about the long-term viability of cryptocurrency systems0.1697Architect/engineer3.106137.77
Other3.305150.57
Mr5—Low adoption rate by SMEs0.0143 *Architect/engineer2.961133.75
Other3.267157.41
Regulatory barriersRg1—No assurance of permanent use of cryptocurrencies in the long run0.7298Architect/engineer3.374141.28
Other3.429144.58
Rg2—Government actions limiting or possibly prohibiting the use of cryptocurrencies0.5049Architect/engineer3.335140.15
Other3.390146.51
Rg3—Incompatibility of cryptocurrency systems with the current legal system0.2984Architect/engineer3.106138.89
Other3.229148.65
Rg4—Possible use of cryptocurrencies in illegal activities0.9089Architect/engineer2.626142.09
Other2.610143.20
* Difference is statistically significant at 0.05 level.
Table 7. Summary of the differences in respondents’ opinions about the barriers against using cryptocurrencies.
Table 7. Summary of the differences in respondents’ opinions about the barriers against using cryptocurrencies.
Barrier CategoryBarrier Against Using CryptocurrenciesRespondent is Knowledgeable about the Basic Principles of EconomicsRespondent is Experienced in the Use of CryptocurrenciesRespondent is not an Engineer nor an Architect
Technical barriersTc1—Lack of technical knowledge about cryptocurrenciesXX+√
Tc2—Possible changes in cryptocurrency protocols+√X+√
Tc3—Integration difficulties with other servicesXXX
Tc4—Irrevocable nature of cryptocurrency systems+√XX
Tc5—Difficulties in converting cryptocurrencies to traditional currenciesXXX
Trust-related barriersTr1—Security gaps due to vulnerable wallet passwords and malicious software+√XX
Tr2—Low maturity of current cryptocurrency technologies+√ +√+√
Tr3—Personal information required by cryptocurrency systemsXXX
Tr4—Easy to commit fraud+√ XX
Market-related barriersMr1—Fluctuations in the value of the cryptocurrency+√XX
Mr2—Limited market opportunitiesX+√X
Mr3—Risky currency compared to traditional currenciesXXX
Mr4—Doubts about the long-term viability of cryptocurrency systems+√XX
Mr5—Low adoption rate by SMEs+√+√+√
Regulatory barriersRg1—No assurance for permanent use of cryptocurrencies in the long runXXX
Rg2—Government actions limiting or possibly prohibiting the use of cryptocurrencies+√ +√X
Rg3—Incompatibility of cryptocurrency systems with the current legal system+√XX
Rg4—Possible use of cryptocurrencies in illegal activitiesX−√X
Notes: A positive check mark (+√) indicates that the barrier is more impactful, whereas a negative check mark (−√) indicates that the barrier is less impactful. A cross mark (x) indicates that there is no statistically significant difference between the opinions of the respondents in the two groups. Difference is statistically significant at 0.05 level.
Publisher’s Note: MDPI stays neutral with regard to jurisdictional claims in published maps and institutional affiliations.

Share and Cite

MDPI and ACS Style

Gurgun, A.P.; Genc, M.I.; Koc, K.; Arditi, D. Exploring the Barriers against Using Cryptocurrencies in Managing Construction Supply Chain Processes. Buildings 2022, 12, 357. https://doi.org/10.3390/buildings12030357

AMA Style

Gurgun AP, Genc MI, Koc K, Arditi D. Exploring the Barriers against Using Cryptocurrencies in Managing Construction Supply Chain Processes. Buildings. 2022; 12(3):357. https://doi.org/10.3390/buildings12030357

Chicago/Turabian Style

Gurgun, Asli Pelin, Mehmet Ilker Genc, Kerim Koc, and David Arditi. 2022. "Exploring the Barriers against Using Cryptocurrencies in Managing Construction Supply Chain Processes" Buildings 12, no. 3: 357. https://doi.org/10.3390/buildings12030357

Note that from the first issue of 2016, this journal uses article numbers instead of page numbers. See further details here.

Article Metrics

Back to TopTop